Fédération Internationale Des Ingénieurs-Conseils
如果由于不可抗力，承包商无法依据合同履行他的任何义务，而且已经根据第19.2款【不可抗力的通知】，发出了相应
的通知，并且由于承包商无法履行此类义务而使其遭受工期的延误和（或）费用的增加，则根据第20.1款【承包商的索赔】，承包商有权： If the Contractor is prevented from performing any of his obligations under the Contract by Force Majeure of which notice has been given under Sub-Clause 19.2 [Notice of Force Majeure], and suffers delay and/or incurs Cost by reason of such Force Majeure, the Contractor shall be entitled subject to Sub-Clause 20.1 [Contractor's Claims] to:
（a） 根据第8.4款【竣工时间的延长】的规定，就任何此类延误获得延长的工期，如果竣工时间已经（或将要）被延误，以及
(a) an extension of time for any such delay, if completion is or will be delayed, under Sub-Clause 8.4 [Extension of Time for Completion], and
（b） 获得任何此类费用的支付款额，如果发生了如第19.1款【不可抗力的定义】中（i）至(iv)段所描述的事件或情况，以及如果在工程所在国发生了如（ii）至(iv)段中所述的事件或情况。
(b) if the event or circumstance is of the kind described in sub-paragraphs (i) to (iv) of Sub-Clause 19.1 [Definition of Force Majeure] and, in the case of subparagraphs (ii) to (iv), occurs in the Country, payment of any such Cost. 在收到此类通知后，工程师应根据第3.5款【决定】对上述事宜表示同意或作出决定。
After receiving this notice, the Engineer shall proceed in accordance with SubClause 3.5 [Determinations] to agree or determine these matters.
8.5 不可抗力对分包商的影响
19.5 Force Majeure Affecting Subcontractor
如果根据有关工程的任何合同或协议，分包商有权在附加的或超出本款规定范围之外的不可抗力发生时解除其义务，则在此类附加的或超出的不可抗力事件或情况发生时，承包商应继续工作，且他无权根据本款解除其履约义务。
If any Subcontractor is entitled under any contract or agreement relating to the works to relief from force majeure on terms additional to or broader than those specified in this Clause, such additional or broader force majeure events or circumstances shall not excuse the Contractor's non-performance or entitle him to relief under this Clause.
8.6 可选择的终止、支付和返回
19.6 Optional Termination, Payment and Release
如果由于不可抗力，导致整个工程的施工无法进行已经持续了84天，且已根据第19.2款【不可抗力的通知】发出了相应的通知，或如果由于同样原因停工时间的总和已经超过了140天，则任一方可向另一方发出终止合同的通知。在这种情况下，合同将在通知发出后7天终止，同时承包商应按照第16.3款【停止工作及承包商的设备的撤离】的规定执行。 If the execution of substantially all the Works in progress is prevented for a continues period of 84 days by reason of Force Majeure of which notice has been given under Sub-Clause 19.2 [Notice of Force Majeure]. or for multiple periods which total more than 140 days due to the same notified Force Majeure, then either Party may give to the other Party a notice of termination of the Contract. In this event, the termination shall take effect 7 days after the notice is given, and the Contractor shall proceed in accordance with Sub-Clause 16.3 [Cessation of Work and Removal of Contractor's Equipment]. 一旦发生此类终止，工程师应决定已完成的工作的价值，并颁发包括下列内容的支付证书：
Upon such termination, the Engineer shall determine the value of the work done and issue a Payment Certificate which shall include:
（a） 已完成的且其价格在合同中有规定的任何工作的应付款额；
(a) the amounts payable for any work carried out for which a price is stated in the Contract;
（b） 为工程订购的，且已交付给承包商或承包商有责任去接受交货的永久设备和材料的费用：当雇主为之付款后，此类永久设备和材料应成为雇主的财产（雇主亦为之承担风险），并且承包商应将此类永久设备和材料交由雇主处置； (b)the Cost of Plant and Materials ordered for the Works which have been delivered to the Contractor, or of which the Contractor is liable to accept delivery: this Plant and Materials shall become the property of (and be at the risk of) the Employer when paid for by the Employer, and the Contractor shall place the same at the Employer's disposal; （c） 为完成整个工程，承包商在某些情况合理导致的任何其他费用或负债；
(c) any other Cost or liability which in the circumstances was reasonably incurred by the Contractor in the expectation of completing the Works;
（d） 将临时工程和承包商的设备撤离现场并运回承包商本国设备基地的合理费用（或运回其他目的地的费用，但不能超过运回本国基地的费用）；以及 (d)the Cost of removal of Temporary Works and Contractor's Equipment from the Site and the return of these items to the Contractor's works in his country (or to any other destination at no greater cost); and （e） 在合同终止日期将完全是为工程雇用的承包商的职员和劳工遣返回国的费用。
第 26 页 共 34 页
Fédération Internationale Des Ingénieurs-Conseils
(e) the Cost of repatriation of the Contractor's staff and labour employed wholly in connection with the Works at the date of
termination.
8.7 根据法律解除履约
19.7 Release from Performance under the Law
除非本条另有规定，如果合同双方无法控制的任何事件或情况（包括，但不限于不可抗力）的发生使任一方（或合同双方）履行他（或他们）的合同义务已变为不可能或非法，或者根据本合同适用的法律，合同双方均被解除进一步的履约，那么在任一方向另一方发出此类事件或情况的通知的条件下：
Notwithstanding any other provision of this Clause, if any event or circumstance outside the control of the Parties (including, but not limited to, Force Majeure) arises which makes it impossible or unlawful for either or both Parties to fulfil its or their contractual obligations or which, under the law governing the Contract, entitles the Parties to be released from further performance of the Contract, then upon notice by either Party to the other Party of such event or circumstance: （a） 合同双方应被解除进一步的履约，但是不影响由于任何以前的违约任一方享有的权利，以及
(a) the Parties shall be discharged from further performance, without prejudice to the rights of either Party in respect of any previous breach of the Contract, and
（b） 如果合同是依据第19.6款的规定终止的，雇主支付给承包商的金额应与根据第19.6款【可选择的终止、支付和返回】终止合同时支付给承包商的金额相同。
(b) the sum payable by the Employer to the Contractor shall be the same as would have been payable under Sub-Clause 19.6 [Optional Termination, Payment and Release] if the Contract had been terminated under Sub-Clause 19.6 9.
索赔、争端和仲裁
Claim, Disputes and Arbitration 9.1 承包商的索赔
20.1 Contractor's Claims
如果承包商根据本合同条件的任何条款或参照合同的其他规定，认为他有权获得任何竣工时间的延长和（或）任何附加款项，他应通知工程师，说明引起索赔的事件或情况。该通知应尽快发出，并应不迟于承包商开始注意到，或应该开始注意到，这种事件或情况之后28天。
If the Contractor considers himself to be entitled to any extension of the Time for Completion and/or any additional payment, under any Clause of these Conditions or otherwise in connection with the Contract, the Contractor shall give notice to the Engineer, describing the event or circumstance giving rise to the claim. The notice shall be given as soon as practicable, and not later than 28 days after the Contractor became aware, or should have become aware, of the event or circumstance.
如果承包商未能在28天内发出索赔通知，竣工时间将不被延长，承包商将无权得到附加款项，并且雇主将被解除有关索赔的一切责任。否则本款以下规定应适用。
If the Contractor fails to give notice of a claim within such period of 28 days, the Time for Completion shall not be extended, the Contractor shall not be entitled to additional payment, and the Employer shall be discharged from all liability in connection with the claim. Otherwise, the following provisions of this Sub-Clause shall apply.
承包商还应提交一切与此类事件或情况有关的任何其他通知（如果合同要求），以及索赔的详细证明报告。
The Contractor shall also submit any other notices which are required by the Contract, and supporting particulars for the claim, all as relevant to such event or circumstance.
承包商应在现场或工程师可接受的另一地点保持用以证明任何索赔可能需要的同期记录。工程师在收到根据本款发出的上述通知后，在不必事先承认雇主责任的情况下，监督此类记录的进行，并（或）可指示承包商保持进一步的同期记录。承包商应允许工程师审查所有此类记录，并应向工程师提供复印件（如果工程师指示的话）。 The Contractor shall keep such contemporary records as may be necessary to substantiate any claim, either on the Site or at another location acceptable to the Engineer. Without admitting the Employer's liability, the Engineer may, after receiving any notice under this Sub-Clause, monitor the record-keeping and/or instruct the Contractor to keep further contemporary records. The Contractor shall permit the Engineer to inspect all these records, and shall (if instructed) submit copies to the Engineer. 在承包商开始注意到，或应该开始注意到，引起索赔的事件或情况之日起42天内，或在承包商可能建议且由工程师批准的此类其他时间内，承包商应向工程师提交一份足够详细的索赔，包括一份完整的证明报告，详细说明索赔的依据以及索赔的工期和（或）索赔的金额。如果引起索赔的事件或情况具有连续影响：
Within 42 days after the Contractor became aware (or should have become aware) of the event or circumstance giving rise to the claim, or within such other period as may be proposed by the Contractor and approved by the Engineer, the Contractor shall send to the Engineer a fully detailed claim which includes full supporting particulars of the basis of the claim and of the extension of time and/or additional payment claimed. If the event or circumstance giving rise to the claim has a continuing effect: （a） 该全面详细的索赔应被认为是临时的； (a) this fully detailed claim shall be considered as interim;
（b） 承包商应该按月提交进一步的临时索赔，说明累计索赔工期和（或）索赔款额，以及工程师可能合理要求的此类进一步的详细报告；以及
第 27 页 共 34 页
Fédération Internationale Des Ingénieurs-Conseils
(b) the Contractor shall send further interim claims at monthly intervals, giving the accumulated delay and/or amount claimed,
and such further particulars as the Engineer may reasonably require; and
（c） 在索赔事件所产生的影响结束后的28天内（或在承包商可能建议且由工程师批准的此类其他时间内），承包商应提交一份最终索赔报告。
(c) the Contractor shall send a final claim within 28 days after the end of the effects resulting from the event or circumstance, or within such other period as may be proposed by the Contractor and approved by the Engineer.
在收到索赔报告或该索赔的任何进一步的详细证明报告后42天内（或在工程师可能建议且由承包商批准的此类其他时间内），工程师应表示批准或不批准，不批准时要给予详细的评价。他可能会要求任何必要的进一步的详细报告，但他应在这段时间内就索赔的原则作出反应。
Within 42 days after receiving a claim or any further particulars supporting a previous claim, or within such other period as may be proposed by the Engineer and approved by the Contractor, the Engineer shall respond with approval, or with disapproval and detailed comments. He may also request any necessary further particulars, but shall nevertheless give his response on the principles of the claim within such time.
每一份支付证明应将根据相关合同条款应支付并已被合理证实的此类索赔金额纳入其中。如果承包商提供的详细报告不足以证明全部的索赔，则承包商仅有权得到已被证实的那部分索赔。
Each Payment Certificate shall include such amounts for any claim as have been reasonably substantiated as due under the relevant provision of the Contract. Unless and until the particulars supplied are sufficient to substantiate the whole of the claim, the Contractor shall only be entitled to payment for such part of the claim as he has been able to substantiate.
工程师应根据第3.5款【决定】，表示同意或作出决定：（i）根据第8.4款【竣工时间的延长】的规定延长竣工时间（在其终止时间之前或之后）（如果有的话），以及（或者）（ii）根据合同承包商有权获得的附加款项（如果有的话）。 The Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine (i) the extension (if any) of the Time for Completion (before or after its expiry) in accordance with Sub-Clause 8.4 [Extension of Time for Completion], and/or (0) the additional payment (if any) to which the Contractor is entitled under the Contract.
除本款的规定外，还有许多其他条款适用于索赔。如果承包商未能遵循本款或其他有关索赔的条款的规定，则在决定竣工时间的延长和（或）额外款项时，要考虑这种未遵循（如果有的话）已妨碍或影响索赔调查的程度，除非根据本款第二段该索赔已被排除。
The requirements of this Sub-Clause are in addition to those of any other Sub-Clause which may apply to a claim. If the Contractor fails to comply with this or another SubClause in relation to any claim, any extension of time and/or additional payment shall take account of the extent (if any) to which the failure has prevented or prejudiced proper investigation of the claim, unless the claim is excluded under the second paragraph of this Sub-Clause.
9.2 争端裁决委员会的委任
20.2 Appointment of the Dispute Adjudication Board
争端应由争端裁决委员会根据第20.4款【获得争端裁决委员会的决定】进行裁决。合同双方应在投标函附录规定的日期内，共同任命一争端裁决委员会。
Disputes shall be adjudicated by a DAB in accordance with Sub-Clause 20.4[Obtaining Dispute Adjudication Board's Decision]. The Parties shall jointly appoint a DAB by the date stated om the Appendix to Tender.
该争端裁决委员会应由具有恰当资格的成员组成，成员的数目可为一名或三名（“成员”），具体情况按投标函附录中的规定。如果投标函附录中没有注明成员的数目，且合同双方没有其他的协议，则争端裁决委员会应包含三名成员。 The DAB shall comprise, as stated in the Appendix to Tender, either one or three suitably qualified persons (\the number is not so stated and the Parties do not agree otherwise, the DAB shall comprise three persons.
如果争端裁决委员会由三名成员组成，则合同每一方应提名一位成员，由对方批准。合同双方应与这两名成员协商，并应商定第三位成员（作为主席）。 If the DAB is to comprise three persons, each Party shall nominate one member for the approval of the other Party. The Parties shall consult both these members and shall agree upon the third member, who shall be appointed to act as chairman.
但是，如果合同中包含了意向性成员的名单，则成员应从该名单中选出，除非他不能或不愿接受争端裁决委员会的任命。 However, if a list of potential members is included in the Contract, the members shall be selected from those on the list, other than anyone who is unable or unwilling to accept appointment to the DAB.
合同双方与唯一的成员（“裁决人”）或三个成员中的每一个人的协议书（包括各方之间达成的此类修正）应编入附在通用条件后的争端裁决协议书的通用条件中。
The agreement between the Parties and either the sole member (\reference the General Conditions of Dispute Adjudication Agreement contained in the Appendix to these General Conditions, with such amendments as are agreed between them.
关于唯一成员或三个成员中的每一个人（包括争端裁决委员会向其征求建议的任何专家）的报酬的支付条件，应由合同
第 28 页 共 34 页
Fédération Internationale Des Ingénieurs-Conseils
双方在协商上述任命条件时共同商定。每一方应负责支付此类酬金的一半。
The terms of the remuneration of either the sole member or each of the three members, including the remuneration of any expert
whom the DAB consults, shall be mutually agreed upon by the Parties when agreeing the terms of appointment. E Party shall be responsible for paying one-half of this remuneration.
在合同双方同意的任何时候，他们可以共同将事宜提交给争端裁决委员会，使其给出意见。没有另一方的同意，任一方不得就任何事宜向争端裁决委员会征求建议。
If at any time the Parties so agree,, they may jointly refer a matter to the DAB fore give its opinion. Neither Party shall consult the DAB on any matter without agreement of the other Party.
在合同双方同意的任何时候，他们可以任命一合格人选（或多个合格人选）替代（或备有人选替代）争端裁决委员会的任何一个或多个成员。除非合同双方另有协议，只要某一成员拒绝履行其职责或由于死亡、伤残、辞职或其委任终止而不能尽其职责，该任命即告生效。
If at any time the Parties so agree, they may appoint a suitably qualified person or persons to replace (or to be available to replace) any one or more members of 1 DAB. Unless the Parties agree otherwise, the appointment will come into effect member declines to act or is unable to act as a result of death, disability, resignation or termination of appointment.
如果发生了上述情况，而没有可替换的人员，委任替换人员的方式与本款中规定的任命或商定被替换人员的方式相同。 If any of these circumstances occurs and no such replacement is available replacement shall be appointed in the same manner as the replaced person W required to have been nominated or agreed upon, as described in this Sub-Clause
任何成员的委任只有在合同双方同意的情况下才能终止，雇主或承包商各自的行动将不能终止此类委任。除非双方另有协议，在第14.12款【结清单】提及的结清单单即将生效时，争端裁决委员会（包括每一个成员）的任期即告期满。 The appointment of any member may be terminated by mutual agreement of bi Parties, but not by the Employer or the Contractor acting alone. Unless other agreed by both Parties, the appointment of the DAB (including each member) shall expire when the discharge referred to in Sub-Clause 14.12 [Discharge] shall be come effective. 9.3 未能同意争端裁决委员会的委任
20.3 Failure to Agree Dispute Adjudication Board 如果下列条件中任一条件适用，即：
If any of the following conditions apply, namely:
（a） 合同双方未能在第20.2款第一段说明的日期就争端裁决委员会的唯一成员的委任达成一致意见，
(a) the Parties fail to agree upon the appointment ofhe sole member of the D by the date stated in the first paragraph of Sub-Clause 20.2,
（b） 合同中任一方未能在此日期，为由三名成员组成的争端裁决委员会提名一名人员（可为另一方接受的）， (b) either Party fails to nominate a member (for approval by the other Party) c DAB of three persons by such date, （c） 合同双方未能在此日期，就第三位成员（担任主席）的委任达成一致意见，或者
(c) the Parties fail to agree upon the appointment of the third member (to act chairman) of the DAB by such date, or
（d） 合同双方在唯一成员或三名成员中的一名成员拒绝履行其职责，或由于死亡、伤残、辞职或其委任终止而不能尽其职责之日后42天内，未能就替代人选的任命达成一致意见，
(d) the Parties fail to agree upon the appointment of a replacement person wit 42 days after the date on which the sole member or one of the three members declines to act or is unable to act as a result of death, disability, resignation termination of appointment, 则专用条件中指定的机构或官方应根据合同一方或双方的要求，并在与合同双方适当协商后，提名该争端裁决委员会成员。该任命应是最终的和具有决定性的。每一方应负责支付该指定的机构或官方的酬金的一半。
then the appointing entity or official named in the Appendix to Tender shall, upon request of either or both of the Parties and after due consultation with both Parties appoint this member of the DAB. This appointment shall be final and conclusive. E,, Party shall be responsible for paying one-half of the remuneration of the appoint entity or official.
9.4 获得争端裁决委员会的决定
20.4 Obtaining Dispute Adjudication Board's Decision
如果在合同双方之间产生起因于合同或实施过程或与之相关的任何争端（任何种类），包括对工程师的任何证书的签发、决定、指示、意见或估价的任何争端，任一方可以将此类争端事宜以书面形式提交争端裁决委员会，供其裁定，并将副本送交另一方和工程师。应说明争端的提交是根据本款作出的。
f a dispute (of any kind whatsoever) arises between the Parties in connection with or arising out of, the Contract or the execution of the Works, including any dispute as to any certificate, determination, instruction, opinion or valuation of the Engineer ( either Party may refer the dispute in writing to the DAB for its decision, with cop to the other Party and the Engineer. Such reference shall state that it is given un this Sub-Clause.
第 29 页 共 34 页
Fédération Internationale Des Ingénieurs-Conseils
对于由三名成员组成的争端裁决委员会，当争端裁决委员会的主席收到此类提交时即认为争端裁决委员会收到了此类提
交。
For a DAB of three persons, the DAB shall be deemed to have received st reference on the date when it is received by the chairman of the DAB.
合同双方应立即向争端裁决委员会提供为对此类争端进行裁决的目的而可能要求的所有此类附加资料、进一步的现场通道和适当的设施。争端裁决委员不应被视为作为仲裁人。
Both Parties shall promptly make available to the DAB all such additional information further access to the Site, and appropriate facilities, as the DAB may require for purposes of making a decision on such dispute. The DAB shall be deemed to be not acting as arbitrator(s).
在争端裁决委员会收到上述争端事宜的提交后84天内，或在争端裁决委员会建议并由双方批准的此类其他时间内，争端裁决委员会应作出决定，该决定应是合理的，并应声明该决定是根据本款作出的。该决定对双方都有约束力，合同双方应立即执行争端裁决委员会作出的每项决定，除非此类决定按下文规定在友好解决或仲裁裁决中得以修改。除非合同已被放弃、撤消或终止，否则承包商应继续按照合同实施工程。
Within 84 days after receiving such reference, or within such other period as may be proposed by the DAB and approved by both Parties, the DAB shall give its decision, which shall be reasoned and shall state that it is given under this Sub-Clause. The decision shall be binding on both Parties, who shall promptly give effect to it unless and until it shall be revised in an amicable settlement or an arbitral award as described below. Unless the Contract has already been abandoned, repudiated or terminated, the Contractor shall continue to proceed with the Works in accordance with the Contract.
如果合同双方中任一方对争端裁决委员会的裁决不满意，则他可在收到该决定的通知后第28天内或此前将其不满通知对方。如果争端裁决委员会未能在其收到此类不满通知后84天（或其他批准的时间）内作出决定，那么合同双方中的任一方均可在上述期限期满后28天之内将其不满通知对方。
If either Party is dissatisfied with the DAB's decision, then either Party may, within 28 days after receiving the decision, give notice to the other Party of its dissatisfaction. If the DAB fails to give its decision within the period of 84 days (or as otherwise approved) after receiving such reference, then either Party may, within 28 days after this period has expired, give notice to the other Party of its dissatisfaction.
在上述任一情况下，表示不满的通知应说明是根据本款发出的，且该通知应指明争端事宜及不满的理由。除非依据本款发出此类通知，否则将不能对争端进行仲裁，但第20.7款【未能遵守争端裁决委员会的决定】和第20.8款【争端裁决委员会的委任期满】所述的情况除外。任何一方若未按本款发出表示不满的通知，均无权就该争端要求开始仲裁。 In either event, this notice of dissatisfaction shall state that it is given under this SubClause, and shall set out the matter in dispute and the reason(s) for dissatisfaction. Except as stated in Sub-Clause 20.7 [Failure to Comply with Dispute Adjudication Board's Decision] and Sub-Clause 20.8 [Expiry of Dispute Adjudication Board's Appointment], neither Party shall be entitled to commence arbitration of a dispute unless a notice of dissatisfaction has been given in accordance with this Sub-Clause.
如果争端裁决委员会已将其对争端作出的决定通知了合同双方，而双方中的任一方在收到争端裁决委员会的决定的第28天或此前未将其不满事宜通知对方，则该决定应被视为最终决定并对合同双方均具有约束力。
If the DAB has given its decision as to a matter in dispute to both Parties, and no notice of dissatisfaction has been given by either Party within 28 days after it received the DAB's decision, then the decision shall become final and binding upon both Parties.
9.5 友好解决
20.5 Amicable both Settlement
按上述第20.4款规定已发出表示不满的通知后，合同双方在仲裁开始前应尽力以友好的方式解决争端。规定，除非合同双方另有协议，否则，仲裁将在表示不满的通知发出后第56天或此后开始，即使双方未曾作过友好解决的努力。 Where notice of dissatisfaction has been given under Sub-Clause 20.4 above, Parties shall attempt to settle the dispute amicably before the commencement of arbitration. However, unless both Parties agree otherwise, arbitration may be commenced on or after the fifty-sixth day after the day on which notice of dissatisfaction was given, even if no attempt at amicable settlement has been made.
9.6 仲裁
20.6 Arbitration
除非通过友好解决，否则如果争端裁决委员会有关争端的决定（如有时）未能成为最终决定并具有约束力，那么此类争端应由国际仲裁机构最终裁决。除非合同双方另有协议，否则：
Unless settled amicably, any dispute in respect of which the DAB's decision (if any) has not become final and binding shall be finally settled by international arbitration. Unless otherwise agreed by both Parties: （a） 该争端应根据国际商会的仲裁规则被最终解决，
(a) the dispute shall be finally settled under the Rules of Arbitration of the International Chamber of Commerce, （b） 该争端应由按本规则指定的三位仲裁人裁决，以及
(b) the dispute shall be settled by three arbitrators appointed in accordance with these Rules, and
第 30 页 共 34 页